Recently in Construction Contracts Category

March 13, 2014

General Contractor Who Delayed Project Held to Have Breached Contract with Subcontractor

A Massachusetts Superior Court recently ruled on a case involving a construction contract between a subcontractor and a general contractor, where the contract included a provision that prohibited the subcontractor from recovering damages from the contractor for a delay in the project. The court held that the "no damages for delay" clause did not prevent the plaintiff-subcontractor from recovering damages from the contractor, as the contractor denied the subcontractor of its only available remedy under the contract.

In Central Ceilings, Inc. v. Suffolk Construction Company, Inc., et al., Central Ceilings, Inc. agreed to furnish labor and material for the drywall and ceiling portions of a project under the control of the general contractor, Suffolk Construction Company. Central agreed to respond to change order requests promptly, and to work under a specific schedule, while Suffolk Construction supervised and coordinated the project and job site.

Continue reading "General Contractor Who Delayed Project Held to Have Breached Contract with Subcontractor" »